Tunnelling projects are complicated, and all parties — the customer, EPC contractors and subcontractors — expect the work to be done on-time and on budget but delays and cost overruns happen.

The NEC contract prescribes that an extension of time, delay and quantum be determined prospectively. The NEC contract requires the contractor to maintain an up-to-date program.

Whether it be assessing insurance claims, variation claims, or the remediation of defective works, a quantum expert is called upon to provide an independent subjective opinion to assist an insurer or a tribunal or, in some cases, to help parties settle a matter outside of formal proceedings.

The term “Contract Program” is often used in reference to the Construction or Contractor’s Program. The Construction (or Contractor’s) Program is basically the execution plan and timeline of how the works under the Contract will be carried out and measured. It should consider the key sequences of work and resource dependencies. It should also, depending on the Contract, identify the critical path and the relationships between the planned activities and interfaces.

This article considers the contractual requirements regarding the most appropriate and accepted method of delay analysis in the commonly used Australian Standard General Conditions of Contract.

A lot has already been written about various delay analysis methodologies. The purpose of this article is to summarise the pros and cons of the most commonly accepted methodologies and highlight where they might best be used.

In this article we are going to consider the differences between mitigation, acceleration, and constructive acceleration. The recent case of V601 v Probuild[1] is of interest, as it demonstrates that a constructive acceleration claim can be successful in certain circumstances.

Project teams are often told to keep daily or even hourly records of events that occur on-site if a claim for additional time and cost arises. These records are known as contemporaneous records in that they are ‘recorded’ when the event occurs.

A common question when demonstrating entitlement to an Extension of Time is, who owns the float?

When considering who owns the float, one first must understand the various definitions of 'float' typically associated with construction projects. Secondly, one must understand the applicable contractual clause relating to claiming an extension of time.

Throughout the next decade, there will no doubt be a worldwide increase in the construction of renewable projects due to government stimulus packages.

An independent delay expert needs to be impartial when engaged in providing early delay and planning advice, so clients understand their actual liabilities or opportunities.

Prolongation or delay costs must reflect the actual losses incurred by a claimant unless otherwise stated in the contract.

More often than not, claimants derive prolongation costs by determining an average daily rate taken from the preliminaries and/or indirect costs listed in the contract and multiplying that rate by the number of days delay.

In this on demand presentation Andrew McKenna and Paul McArd discuss what a global claim is and how they can be avoided by using quantum and delay experts.

Delay analysis is not the “dark art” it is often perceived to be. It is simply how to prove the purported delaying events impact (the cause) on time (the effect). The analysis must provide a clear and succinct distinction of the chain of events that have hindered progress and ultimately caused the delay(s) to completion.

An independent quantum expert needs to be impartial when engaged in providing early quantum advice, so clients understand their actual liabilities or opportunities.

When drafting a quantum and/or delay claim based on several events, claimants commonly use inference rather than causation to build their arguments. This approach is sometimes used by claimants as they tend to focus on the monetary amounts lost and/or the delays they have incurred, rather than identifying causation.